Terms & Conditions

Effective date: October 15, 2026

EZ Air 4×4
7225 N 110th Ave Suite 9, Glendale, AZ 85307

These Terms and Conditions (“Terms”) govern all purchases placed with EZ Air 4×4 (“Seller,” “we,” “us”) on or after the effective date above.

By placing an order through ezair4x4.com, you (“Buyer,” “Customer,” “you”) affirmatively agree to these Terms, together with the Returns Policy, Warranty Policy, and Shipping Policy displayed on ezair4x4.com at the time of purchase, each of which is incorporated by reference.

ACCEPTANCE OF ORDER

These Terms, together with the purchase order submitted by Buyer, shall constitute the agreement between Buyer and Seller with respect to the purchase of any product sold in our store (the “Goods”). The Order becomes effective upon the first of: (a) Seller’s written acknowledgment of acceptance; (b) any performance by Seller under the Order; or (c) the passage of ten (10) days after Seller’s receipt of the Order without written rejection.

DELIVERY

After payment in full, Seller shall deliver the Goods to the Delivery Location on or around the Delivery Date specified in the Order.

INSPECTION

Buyer reserves the right to inspect the Goods within two (2) days after the Delivery Date. If Buyer reasonably determines that the Goods are defective or nonconforming, Buyer may reject the Goods within that period, in which case Seller shall promptly replace or repair the nonconforming parts pursuant to Section 5.

PRICE AND PAYMENT

The price of the Goods is the price stated on the face of the Order. Buyer shall pay in full upon the agreed payment date, which shall be prior to Delivery.

LIMITED WARRANTY

For a period of one (1) year from the first Delivery Date (the “Initial Limited Warranty Period”), Seller will repair or replace defective parts free of charge. For the four (4) years thereafter (the “Extended Limited Warranty Period”), Seller will repair or replace defective parts at Seller’s production cost, with Buyer responsible for shipping.

The Limited Warranty does not apply to problems arising out of: (a) modification or damage by Buyer or a third party; (b) operation or use other than as instructed; (c) combination with unapproved technology; (d) negligence or abuse; (e) breach of the Agreement; or (f) circumstances outside Seller’s reasonable control. Aesthetic changes, Buyer-caused damage, and normal wear and tear are excluded. This Section sets forth Seller’s entire obligation and liability for the Limited Warranty.

DISCLAIMER OF WARRANTIES

EXCEPT AS SET FORTH IN SECTION 5, THE GOODS ARE PROVIDED “AS-IS.” SELLER AND ITS AFFILIATES DISCLAIM ALL IMPLIED AND STATUTORY WARRANTIES, INCLUDING MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR A PARTICULAR PURPOSE, AND ANY WARRANTIES ARISING FROM COURSE OF DEALING OR TRADE PRACTICE. NEITHER SELLER NOR ITS SUBCONTRACTORS IS LIABLE FOR ANY SPECIAL, INCIDENTAL, CONSEQUENTIAL, INDIRECT, OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, LOST REVENUE, OR THE COST OF SUBSTITUTE EQUIPMENT.

ASSUMPTION OF RISK / RELEASE AND WAIVER OF LIABILITY

Use of the Goods, including installing them on a motor vehicle and inflating or deflating its tires, is at Buyer’s own risk. Buyer assumes the risk of any personal, physical, or property injury or damage. Buyer represents that they have read all warnings and safety precautions provided by Seller, including: never exceeding the maximum pressure printed on the tire or the pressure limits set by the vehicle and tire manufacturers; checking every tire with a gauge before driving; keeping hands, hair and loose clothing clear of moving, pressurized and hot parts; that compressors, hoses and fittings become hot in use; and that the Goods are not a substitute for a professional inspection of tires, wheels and valves.

Buyer releases and discharges Seller (and its affiliates, employees, agents, and subcontractors) from any and all claims or causes of action (known or unknown) arising out of the use of the Goods, to the fullest extent permitted by law. This release is not intended as a release of claims of gross negligence or intentional acts.

CHANGE ORDER

Any changes to the Order shall be agreed in writing by both parties.

TERMINATION

Either party may terminate the Order for any reason upon prior written notice, provided shipment has not occurred.

SHIPPING TERMS

Delivery shall be made in accordance with the Terms of the Order. Buyer is responsible for all delivery costs, including shipping, freight, duties, and similar taxes.

  • 10.1 Methods: Seller ships using the method specified at purchase but reserves the right to use alternatives when necessary.
  • 10.2 Costs: Shipping costs are calculated based on size, weight, destination, and method. Quoted costs are estimates; actual costs may vary.
  • 10.3 Delivery Time: Seller makes reasonable efforts to deliver timely but does not guarantee delivery dates and is not liable for delays caused by circumstances beyond its control.

TAXES

Prices are exclusive of taxes. Buyer is solely responsible for all federal, state, and local taxes, including sales, use, and consumption taxes.

TITLE AND RISK OF LOSS

Risk of loss remains with Seller and title does not pass to Buyer until the Goods are delivered to and accepted by Buyer at the Delivery Location.

WAIVER AND RELEASE OF LIENS

Upon Seller’s receipt of amounts properly invoiced, Seller waives and releases all lien rights and shall obtain prompt removal of any lien fixed against Buyer.

RELATIONSHIP OF THE PARTIES

Seller is an independent contractor. Nothing in this agreement creates any agency, partnership, employment, or fiduciary relationship.

CHARGEBACK CLAUSE

Buyer agrees that filing a chargeback, payment-card dispute, or other reversal of payment with any card issuer, bank, or payment processor in contradiction of the Returns, Warranty, or Shipping policies expressly agreed to at checkout constitutes a material breach of this agreement.

In the event of such a chargeback, Buyer shall be liable for:

  • (a) the full amount of the disputed transaction;
  • (b) a $75 chargeback administrative fee;
  • (c) reasonable attorneys’ fees and costs of collection in any proceeding where attorneys are permitted by court rule; and
  • (d) any merchant-processor penalties, fees, or losses incurred by Seller as a direct or indirect result of the chargeback.

Seller may pursue recovery of these amounts in the forum specified in Section 16.

GOVERNING LAW AND VENUE

This agreement and any terms related thereto shall be governed by the laws of the State of Arizona, without regard to conflict-of-law principles.

Any dispute, claim, or controversy arising out of or relating to this agreement, any purchase, the Goods, or the parties’ relationship shall be brought exclusively in the courts of Maricopa County, Arizona: specifically:

  • the Maricopa County Justice Court, small-claims division for matters at or below $3,500 (per ARS §22-503);
  • the Maricopa County Justice Court, civil division for matters above $3,500 and at or below $10,000;
  • the Superior Court of Arizona, Maricopa County for matters above $10,000.

Each party irrevocably consents to the personal jurisdiction of those courts and waives any objection based on forum non conveniens, lack of personal jurisdiction, or improper venue.

CLASS-ACTION AND REPRESENTATIVE-ACTION WAIVER

Each party waives any right to participate in any class, collective, or representative action arising out of or relating to this agreement. All claims must be brought in the party’s individual capacity and not as a plaintiff or class member in any purported class or representative proceeding.

JURY-TRIAL WAIVER

To the extent permitted by law, and to the extent any claim is heard in a court permitting jury trials, each party waives its right to trial by jury in any action arising out of or relating to this agreement.

FEE-SHIFTING

In any action to enforce this agreement in which attorneys are permitted by court rule, the prevailing party is entitled to recover its reasonable attorneys’ fees and costs (including expert and investigation costs).

NOTICES

All notices shall be in writing and addressed to:

EZ Air 4×4
Attn: Legal Department
7225 N 110th Ave Suite 9
Glendale, AZ 85307

Notices are effective upon actual receipt, provided they are delivered by personal delivery, nationally recognized overnight courier, or certified or registered mail (return receipt requested).

INCORPORATION OF POLICIES

The Returns Policy, Warranty Policy, and Shipping Policy as displayed on ezair4x4.com at the time of purchase are incorporated into this agreement by reference. Buyer acknowledges affirmative agreement to each at checkout.

INCONSISTENT TERMS

These Terms shall supersede and prevail over any other prior terms and conditions. Any separate written overriding agreement signed by both parties shall govern over the terms of this agreement.

SEVERABILITY

If any term or provision of this agreement is found invalid, illegal, or unenforceable in any jurisdiction, such invalidity shall not affect any other term of this agreement or invalidate or render unenforceable such term in any other jurisdiction.

MISCELLANEOUS

Buyer shall not assign, transfer, delegate, or subcontract any of its rights or obligations under this agreement without Seller’s prior written consent. No modification, alteration, or amendment shall be binding unless agreed in writing and signed by Seller. No waiver by any party shall be effective unless explicitly set forth in writing and signed by the waiving party.